Our comprehensive services include but are not limited to:

• Complete home and office interior design
• Texture painting and wall treatments
• Wooden flooring installation and maintenance
• Interior curtains and window treatments
• Tile and marble work installation
• Custom furniture design and manufacturing
• Lighting design and installation
• Space planning and 3D visualization
• Project management and execution
• Post-completion maintenance services

Services are subject to:

• Availability of skilled personnel and materials
• Site accessibility and safety conditions
• Compliance with local building regulations
• Client approval at each project phase
• Weather conditions for certain installations

• Initial consultation to understand client requirements
• Site survey and technical assessment
• Feasibility analysis and design recommendations
• Budget estimation and timeline planning

• Conceptual design development
• 3D visualization and material selection
• Client approval at each design stage
• Final design documentation and specifications

• Detailed project contract with specifications
• Work commencement upon signed agreement
• Regular progress updates and milestone reviews
• Quality control and client inspections

Project costs are determined based on:

• Design complexity and project scope
• Material specifications and quality grades
• Labor requirements and specialized skills
• Timeline constraints and project urgency
• Site conditions and accessibility factors

Payment terms and schedule will be specified in the booking form at the time of booking and will form part of the project contract. The payment structure will be customized based on:

• Project scope and complexity
• Total contract value
• Timeline and milestones
• Material requirements
• Client preferences and cash flow considerations

The detailed payment schedule, including amounts and due dates, will be clearly outlined in the booking form and project agreement signed by both parties.

Clients are responsible for:

• Government taxes and duties as applicable
• Structural modifications requiring separate approvals
• Premium materials beyond standard specifications
• Changes in project scope after commencement
• Site preparation and utility connections

Clients must ensure:

• Unhindered site access for workers and materials
• Safe working environment and necessary permits
• Existing furniture removal and storage arrangements
• Utility connections and infrastructure readiness
• Compliance with society/building regulations

Clients must provide:

• Timely approvals for designs and material selections
• Clear communication of preferences and requirements
• Access to decision-makers throughout the project
• Prompt resolution of any concerns or modifications

We commit to:

• Use of quality materials from certified suppliers
• Skilled workmanship adhering to industry standards
• Regular quality checks and progress monitoring
• Compliance with safety and building regulations
• Timely project completion as per agreed timeline

We maintain:

• Qualified and experienced design professionals
• Licensed contractors and skilled craftsmen
• Insurance coverage for workers and materials
• Adherence to environmental and safety protocols

• Structural Work: 2 years from completion
• Electrical and Plumbing: 1 year from completion
• Painting and Finishes: 1 year from completion
• Furniture and Fittings: As per manufacturer warranty
• Hardware and Accessories: 6 months from installation

• Original manufacturer warranties apply to all materials
• Replacement of defective materials at no additional cost
• Regular maintenance guidelines provided
• Post-warranty support available at nominal charges

• All original designs remain intellectual property of Maity Decor
• Clients receive usage rights for the specific project
• Designs cannot be reproduced without written consent
• Custom designs created specifically for clients become their property

• Respect for third-party intellectual property rights
• Proper licensing for patented or copyrighted materials
• Client responsibility for any unauthorized usage

Our liability is limited to:

• Direct costs related to defective workmanship
• Replacement or repair of non-conforming work
• Refund of payments for undelivered services
• Maximum liability capped at the total contract value

We are not liable for:

• Consequential or indirect damages
• Loss of business or anticipated profits
• Delays due to circumstances beyond our control
• Damage to pre-existing conditions not disclosed
• Third-party claims or intellectual property disputes

Neither party shall be liable for delays or failures in performance due to:

• Natural disasters, floods, earthquakes, or severe weather
• Government actions, regulations, or policy changes
• Labor strikes, lockouts, or industrial disputes
• Material shortages or supply chain disruptions
• Pandemic, epidemic, or public health emergencies
• Any other circumstances beyond reasonable control

• Before Work Commencement: 90% refund after deducting design charges
• During Design Phase: 70% refund after deducting completed work value
• During Execution Phase: Refund based on work not executed
• Post 50% Completion: No refund eligible

• Full refund of all payments received
• Compensation for any inconvenience caused
• Assistance in finding alternative service providers

We collect and use client information for:

• Project planning and execution purposes
• Communication regarding project progress
• Legal and regulatory compliance requirements
• Marketing communications (with consent)

• Secure storage of client information
• Limited access to authorized personnel only
• No sharing with third parties without consent
• Data retention as per legal requirements

• Initial resolution through direct communication
• Mediation through mutually agreed mediator
• Good faith efforts to resolve disputes promptly

• Jurisdiction limited to courts in Durgapur, West Bengal
• Disputes governed by Indian laws and regulations
• Arbitration as per Arbitration and Conciliation Act, 2015
• English language for all legal proceedings

These Terms are governed by the laws of India and subject to the jurisdiction of courts in Durgapur, West Bengal.

If any provision of these Terms is deemed invalid or unenforceable, the remaining provisions shall continue in full force and effect.

These Terms constitute the entire agreement between the parties and supersede all prior negotiations, representations, or agreements.

These Terms may only be modified through written agreement signed by both parties. Updates to general terms will be posted on our website with effective dates.

Clients cannot assign their rights or obligations under these Terms without our written consent. We may assign our rights to affiliated companies or successors.

• Adherence to Indian Contract Act, 1872
• Compliance with Consumer Protection Act, 2019
• GST registration and tax compliance
• Environmental clearances where applicable
• Building bye-laws and municipal regulations

• Bureau of Indian Standards (BIS) compliance
• National Building Code of India adherence
• Safety protocols as per Factories Act, 1948
• Quality standards for materials and workmanship

For any queries, concerns, or clarifications regarding these Terms:

• MDC Decor Private Limited 3/4, Central Park, City Centre, Bardhaman, Durgapur Mc, West Bengal, India - 713216
• Phone: +91 933 255 2770
• Email: contact@mdcdecor.in
• Website: www.maitydecor.com
• Business Hours: Monday to Sunday, 9:00 AM to 7:00 PM

By engaging our services or using our website, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions. These Terms are effective from June 19, 2025, and supersede all previous versions.

For any legal advice or clarification, clients are advised to consult with qualified legal professionals.

This document has been prepared in accordance with Indian laws and regulations. Regular updates ensure compliance with changing legal requirements and industry best practices.